JURITEXT000006962542 Généré par l'IA

Contractor Liability for Delayed Performance Despite Authority Modification

Numéro de cause JURITEXT000006962542

Autorité / Tribunal Cour de cassation

Juridiction

France (FR)

Date de la décision 1963-05-08

Issue du litige Rejeté (Dismissed)

Ouvrir la source officielle Version Markdown lisible par machine (.md)

Synthèse Legislator

Généré par l'IA

A party, obligated by a contract to complete construction work by a specified date, sought to invoke the doctrine of *force majeure* to be excused from liability for delays, claiming that a subsequent, unforeseen modification of the plans by the contracting authority constituted an insurmountable obstacle. The court rejected this appeal, reasoning that while the authority's modifications did alter the execution conditions, they did not render the performance absolutely impossible, thus the contractor remained responsible for timely completion despite the changes.

Regeste Legislator

Généré par l'IA

Contractor Liability for Delayed Performance Despite Authority Modification: The court rejected this appeal, reasoning that while the authority's modifications did alter the execution conditions, they did not render the performance absolutely impossible, thus the contractor remained responsible for timely completion despite the changes.

Mots-clés

Généré par l'IA

responsabilité de l'entrepreneur notion de pouvoir adjudicateur obligation de construire contrat de sous-traitance obligation de prester de l'assureur retard injustifié

Généré par l'IA

JURITEXT000006955577

Contractor Late Performance Damages

JURITEXT000006952803

Building Owner v. Contractor: Contractual Delay Justification Beyond Force Majeure

89-19280

Supplier Delay Liability and Client Modification of Requirements

21-20804

Construction Delay Liability and Damage Calculation in Sale Contract Dispute

92-14540

Contractor v. Subcontractor: Delay Damages and Contractual Time Limits