JURITEXT000006954568 Généré par l'IA

Contractor Breach of Construction Contract Liability Appeal

Numéro de cause JURITEXT000006954568

Autorité / Tribunal Cour de cassation

Juridiction

France (FR)

Date de la décision 1960-03-18

Issue du litige Rejeté (Dismissed)

Ouvrir la source officielle Version Markdown lisible par machine (.md)

Synthèse Legislator

Généré par l'IA

A dispute arose regarding the liability for damages following the failure of a contractor to complete work according to specifications and deadlines stipulated in a contract for the construction of a structure, despite the owner having made partial payments. The court rejected the appeal, affirming the lower court's decision that the contractor was indeed at fault for the breach of contract due to non-performance and delays, thus upholding the determination of liability and the resulting obligation to compensate the owner for the damages incurred.

Regeste Legislator

Généré par l'IA

Contractor Breach of Construction Contract Liability Appeal: The court rejected the appeal, affirming the lower court's decision that the contractor was indeed at fault for the breach of contract due to non-performance and delays, thus upholding the determination of liability and the resulting obligation to compensate the owner for the damages incurred.

Mots-clés

Généré par l'IA

responsabilité de l'entrepreneur versement de dommages-intérêts défauts de construction interprétation du contrat adjudication de marché de travaux manquement du bailleur

Généré par l'IA

JURITEXT000006946146

Construction Company Breach of Contract for Missed Deadline

JURITEXT000006964104

Contractor Delay and Material Breach of Construction Contract

JURITEXT000006963964

Contractor v. Subcontractor: Breach of Construction Specifications

15-13467

Construction Contract Dispute: Builder Liability for Defects and Subcontractor Summons Irregularity

00-18360

Owner v. Contractor: Construction Defects and Insurance Liability Appeal