JURITEXT000006946146 Généré par l'IA

Construction Company Breach of Contract for Missed Deadline

Numéro de cause JURITEXT000006946146

Autorité / Tribunal Cour d'appel de Nancy

Juridiction

France (FR)

Date de la décision 2005-09-05

Issue du litige Rejeté (Dismissed)

Ouvrir la source officielle Version Markdown lisible par machine (.md)

Synthèse Legislator

Généré par l'IA

A plaintiff sought damages after a construction company failed to meet a contractual deadline for completing work, leading to financial losses; the appellate court upheld the lower court's decision to grant damages, reasoning that the agreed-upon completion date constituted an obligation of result, and the contractor's failure to meet this deadline, without demonstrating a force majeure event, constituted a breach of contract entitling the client to compensation for resulting prejudice.

Regeste Legislator

Généré par l'IA

Construction Company Breach of Contract for Missed Deadline: A plaintiff sought damages after a construction company failed to meet a contractual deadline for completing work, leading to financial losses; the appellate court upheld the lower court's decision to grant damages, reasoning that the agreed-upon completion date constituted an obligation of result, and the contractor's failure to meet this deadline, without demonstrating a force majeure event, constituted a breach of contract entitling the client to compensation for resulting prejudice.

Mots-clés

Généré par l'IA

inexécution d'une obligation contractuelle inobservation du délai entrepreneur contrat d'organisation dépassement du devis de construction perte de travail

Généré par l'IA

JURITEXT000006964104

Contractor Delay and Material Breach of Construction Contract

JURITEXT000006954568

Contractor Breach of Construction Contract Liability Appeal

15-17328

Construction Company v. Property Owner: Contractual Deadlines and Delay Liability in Renovation Dispute

JURITEXT000006964098

Contractor Liability for Third-Party Delay

87-17876

Owner v. Builder: Contractual Deadline and Delay Causation